Terms of Service

NexDevo ("we", "us", or "our") is a digital agency based in Meknes, Morocco, providing web development, UI/UX design, SEO & GEO, AI integration, automation and DevOps services.

Contact us at info@nexdevo.com or BMO Bloc F, Alliouate, Meknes, Morocco.

You may use this website for lawful purposes only. You agree not to misuse the website, attempt to gain unauthorized access to our systems, or use the website in any way that could damage, disable or impair its operation.

Information on this website about our services is provided for general information purposes. Specific terms, pricing, timelines and deliverables are defined in individual proposals, quotes or contracts agreed with each client. In the event of any conflict, the signed agreement prevails over these terms.

Payment terms, including deposits, milestones and final balances, are set out in each proposal or contract. Unless otherwise agreed, projects begin only after the initial deposit is received. Late payments may result in suspension of work until the outstanding amount is settled.

Until full payment is received, all work products remain the property of NexDevo. Upon full payment, ownership of the final deliverables transfers to the client. NexDevo retains the right to display the work in its portfolio unless a non-disclosure agreement states otherwise.

All content on this website — including text, graphics, logos and code — is the property of NexDevo and may not be reproduced without our written permission.

You agree to provide accurate information and timely feedback during a project, and to ensure you have the rights to any content or materials you provide for use in your project. Delays in providing required materials may affect project timelines.

Our services may involve third-party tools, platforms or services (for example hosting providers, payment processors, or AI APIs). These are governed by their own terms of service, and we are not responsible for their availability, pricing or policies.

To the maximum extent permitted by law, NexDevo shall not be liable for any indirect, incidental, special or consequential damages arising from the use of this website or our services. Our total liability shall not exceed the amount paid to us for the specific service in question.

The website and services are provided "as is" without warranties of any kind, whether express or implied. While we aim for accuracy, we do not guarantee that the website will be uninterrupted, error-free, or that search rankings or business results will be achieved.

We may update these terms from time to time. Changes take effect when posted on this page, and continued use of the website or services constitutes acceptance of the updated terms.

These terms are governed by the laws of the Kingdom of Morocco, and any disputes shall be subject to the jurisdiction of the courts of Meknes.

If you have any questions about these terms, contact us at info@nexdevo.com.